JBCC Small and Simple Works Contract

Table Of Contents

TABLE OF CONTENTS
1.0 DEFINITIONS AND INTERPRETATION
Definitions
Interpretation
Offer and acceptance
Documents
Assignment
2.0 INSURANCES AND INDEMNITIES
3.0 EXECUTION, SETTING OUT AND PROGRAMME
Execution
Setting out
Programme
4.0 DIRECT CONTRACTORS
5.0 PAYMENT
6.0 ADJUSTMENT OF THE CONTRACT VALUE AND FINAL ACCOUNT
7.0 CONTRACT INSTRUCTIONS
8.0 COMPLETION AND DEFECTS LIABILITY PERIOD
Practical completion
Final completion and defects liability period
9.0 REVISION OF THE DATE FOR PRACTICAL COMPLETION AND
PENALTIES
10.0 SUSPENSION AND TERMINATION
Suspension by the contractor
Termination
Termination procedure
11.0 DISPUTES
Settlement by the parties
Mediation
Adjudication
Arbitration
General
12.0 CONTRACT DATA
12.1 INFORMATION BY THE EMPLOYER
Project information
JBCC General Preliminaries - selections
Changes made to to JBCC documentation
Tender closing
12.2 INFORMATION BY THE CONTRACTOR
Contractor information
Tender Conditions, amount compilation and qualifications